Legals January 22, 2018

Print Article

Best Hill Booster Pump Station - REBID CITY OF COEUR D'ALENE WATER DEPARTMENT Notice of Advertisement for Bids Sealed Bids will be received by the City of Coeur d'Alene at the office of the City Clerk, 710 E. Mullan Avenue, Coeur d'Alene, Idaho 83814 on or before the 14th of February 2018 until the hour of 2:00 p.m. for the Best Hill Booster Pump Station REBID Project. Bids will be opened in the Conference Room 5 at Coeur d'Alene City Hall and read aloud at said time and date. All interested individuals are welcome to attend. The project consists of construction of a new booster pump station and associated site work. Bid forms, bidder's instructions, specifications, and contract forms may be examined at the following locations: * City Clerk's Office, City of Coeur d'Alene, 710 Mullan Avenue, Coeur d'Alene, Idaho * J-U-B ENGINEERS, Inc., 7825 Meadowlark Way, Coeur d'Alene, Idaho * Associated General Contractors, E. 4935 Trent, Spokane, Washington * Spokane Regional Plan Center, 209 N. Havana Street, Spokane, Washington * Idaho Associated General Contractors, 1649 W. Shoreline Dr. Suite 100, Boise, ID Copies may be obtained at the office of the City Clerk, 710 Mullan Avenue, Coeur d'Alene, Idaho, (208) 769-2229 upon payment of Fifty Dollars and 00/100 ($50.00), non-refundable, for each set. The standard set of contract documents includes reduced (half size) drawings. Full-color copies of the plans must be used for Bidding purposes. A Pre-Bid Conference will be held at 1:30 p.m. on January 31, 2018, at J-U-B ENGINEERS, Inc. at 7825 Meadowlark Way, Coeur d'Alene ID. All bids shall be presented or otherwise delivered to the City Clerk in a sealed envelope and marked on the outside as "Bid for Best Hill Booster Pump Station - REBID". All bids shall contain one of the following forms of bidder's security in an amount equal to 5% of the amount bid: a) Cash, b) Cashiers Check made payable to the City, c) Certified Check made payable to the City, or d) Bidder's Bond executed by a qualified Idaho Surety Company, made payable to the City. Bids will remain subject to acceptance for thirty five (35) days after the bid opening. The City, in accordance with the provisions of Title VI of the Civil Rights Act of 1964 (78 Stat.252, 42 US. C. 2000d to 2000d-4) and the Regulations, hereby notifies all bidders that it will affirmatively ensure that any contract entered into pursuant to this advertisement, disadvantaged business enterprises will be afforded full and fair opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, or national origin in consideration for an award. Davis-Bacon Wage Rates will not be applicable to this project. The right is reserved to reject any or all Bids. Questions during bidding should be directed to Michelle Johnson, P.E. at J-U-B ENGINEERS, Inc. at 7825 Meadowlark Way; Coeur d'Alene, Idaho; phone 208-762-8787; fax 208-762-9797; email mjohnson@jub.com. Dated this 11th day of January, 2018. Renata McLeod, City Clerk, CMC CDA LEGAL 8908 JANUARY 22, 29, 2018

NOTICE OF REQUEST FOR QUALIFICATIONS MEMORIAL FIELD SOFTBALL GRANDSTAND REHABILITATION & IMPROVEMENTS FOR THE CITY OF COEUR D'ALENE Statements of Qualifications (SOQ) for the City of Coeur d'Alene MEMORIAL PARK GRANDSTANDS will be received at the office of the City Clerk, 710 E. Mullan Avenue, Coeur d'Alene, Idaho 83814, until 2:00 p.m., Local Time, Monday, February 5, 2018, for the purpose of establishing a pre-approved Provider list of professional design, engineering, and consultant services pursuant to Idaho Code 67-2320. By this Request for Qualifications, the City seeks SOQ's from professional consulting/engineering firms and individuals with expertise in structural rehabilitation and design. All firms and individuals wishing to submit must demonstrate their capacity, competency, experience, local responsiveness, and availability of personnel and equipment resources. A committee will be formed to select the best candidate for a design/build rehabilitation of the Memorial Park Grandstands. All SOQ's shall be presented or otherwise delivered to the City Clerk under seal with a statement marked on the outside thereof identifying the project. Questions regarding this Request for Qualifications should be directed to Bill Greenwood at (208) 769-2251. The project limits are generally defined as the Memorial Park Softball Grandstand rehabilitation & improvements, and the scope of the project includes, but is not limited to a Structural Engineering Assessment (SEA) for recommendations for rehabilitation vs. replacement, a preliminary opinion of probable cost for the work scenarios proposed in the SEA; and a complete set of Construction Documents representing the selected approach. Preliminary design concepts have been previously developed proposing the incorporation of new restrooms, locker/team changing rooms, dugout, and concessions. These design concepts are anticipated to be refined and incorporated into the final Construction Documents. Statement of Qualification forms, Respondent's instructions, and specifications are available on CD to interested individuals and firms at the Customer Service Center at City Hall, Attn: Kelley Setters, 710 E. Mullan Avenue, Coeur d'Alene, ID 83814 (ksetters@cdaid.org). A non-refundable charge of $15.00 will be collected for each set. SOQ's faxed, emailed, or received after the date and time stated above will not be accepted. SOQ's will not be publicly opened. The City, in accordance with the provisions of Title VI of the Civil Rights Act of 1964 (78 Stat.252, 42 US. C. 2000d to 2000d-4) and the Regulations, hereby notifies all responders that it will affirmatively ensure that any contract entered into pursuant to this advertisement, disadvantaged business enterprises will be afforded full and fair opportunity to submit SOQ's and will not be discriminated against on the grounds of race, color, or national origin. Prevailing wages are NOT required for this project. The City of Coeur d'Alene reserves the right to reject any or all SOQ's. Date: January 12, 2018 /S/: Renata McLeod City Clerk CDA LEGAL 8940 JANUARY 22, 29, 2018

NOTICE TO CREDITORS (I.C. SECTION 15-3-801) CASE NO. CV-17-9364 IN THE DISTRICT COURT OF THE FIRST JUDICIAL DISTRICT OF THE STATE OF IDAHO, IN AND FOR THE COUNTY OF KOOTENAI IN THE MATTER OF THE ESTATE OF JULIA ANN FREE, Deceased. NOTICE IS HEREBY GIVEN that Carolyn Sue Fall has been appointed Personal Representative of the above-named Decedent. All persons having claims against the Decedent or the Estate are required to present their claims within four (4) months after the date of the first publication of this Notice or said claims will be forever barred. Claims must be presented to the undersigned at the address indicated, and filed with the Clerk of the Court. DATED this 11th day of January, 2018. /S/: JOHN F. MAGNUSON, ISB #4270 Attorney for Carolyn Sue Fall Personal Representative to the Estate of Julia Ann Free P.O. Box 2350 Coeur d'Alene, ID 83816-2350 Telephone: (208) 667-0100 Facsimile: (208) 667-0500 CDA LEGAL 8903 JANUARY 15, 22, 29, 2018

Notice of Public Hearing NOTICE IS HEREBY GIVEN that the Kootenai County Board of Commissioners will hold a public hearing per Idaho Codes 31-1604 and 31-1605 on Tuesday, January 23, 2018 at 2:00 pm, in the Boardroom, Kootenai County Administration Building, 451 Government Way, Coeur d'Alene, Idaho. The purpose of the hearing is to consider the following adjustments to the Fiscal Year 2017 budget to reflect unscheduled revenues. Any taxpayer may appear and be heard upon any part of said tentative budget, published below, at this time. WHEREAS, Idaho Code 31-1605 provides that the Board of County Commissioners may adjust the budget to reflect unscheduled revenues from Federal, State, or other sources; Kootenai County Board of Commissioners will consider that the Fiscal Year 2017 budget shall be adjusted to reflect the following unscheduled revenues: FY 2017 Kootenai County Adopted Budget $ 96,343,347 EMS and Internal Service Fund Excluded Unscheduled Revenues Capital Project Carryforward from FY16 (Resolution 2016-115) $ 1,316,824 Grant Awards and Amendments $ 9,749,539 Donations $ 85,250 Trust Appropriation $ 11,716 Fund Balance Appropriation $ 2,153,720 Total Unscheduled Revenues $ 13,317,049 FY2017 Kootenai County Amended Budget $109,660,396 EMS and Internal Service Fund Excluded Additional information is available from the Kootenai County Commissioners' and Auditor's Offices at the County Administration Building, 451 Government Way, Coeur d'Alene, Idaho. CDA LEGAL 8897 JANUARY 15, 22, 2018

NOTICE TO GENERAL CONTRACTORS Bid proposals will be received - BY: ML ARCHITECT & ASSOCIATES AT: ML ARCHITECT & ASSOCIATES 607 E 6th Avenue POST FALLS, IDAHO 83854 FOR: POST FALLS POLICE DEPARTMENT ANIMAL SAFETY BUILDING 1717 E POLSTON AVENUE POST FALLS, IDAHO 83854 AS FOLLOWS: The City of Post Falls Police Department (hereafter known as PFPD) will receive sealed bids for the PFPD Animal Safety Building in Post Falls, Idaho at the City of Post Falls, City Hall Building 408 N Spokane St., Post Falls, Idaho 83854 until 2:00 pm Pacific Daylight Time on Thursday, February 7, 2018. The bids will be publicly opened. Bids, hand delivered or mailed, shall be delivered to the City Clerk at the City of Post Falls, 408 N Spokane St, Post Falls Idaho 83854. Bids shall be plainly marked "BID ENCLOSED - PFPD ANIMAL SAFETY BUILDING" along with the name and address of the bidder. The PFPD Animal Safety Building is a new building for the use of animal safety, kennels, and office area. Work as indicated in the Bidding Documents. The bid alternates include a backup generator system, kennel system with cmu block/chainlink fence, and second ceiling hung gas unit heater in kennel area. There will be NO pre-bid meeting or site walk-thru. It is the responsibility of the bidders to examine the site. For site access, contact the PFPD. The Bidding Documents may be examined at the following locations: * Associated General Contractors, 3895 N. Schreiber Way, Suite 100, Coeur d'Alene, Idaho 83815 Emailed upon request, by General Contractors only, by contacting ML Architect The following criteria will be used in the selection of proposals: 1. Price Contractors shall base all proposals off this document, the attached Contract Drawings, Scope of Work, Supplementary and General Conditions, Technical Specifications with all appended documents and any addendums issued. The Contractor will be required to maintain Contractors Liability Insurance to include Workman's Compensation (statutory), Employer's Liability ($1,000,000 minimum) and Comprehensive General Liability (minimum of $1,000,000 combined single limits for bodily injury and property damage). Contractor will include a certificate of insurance with the bid. The Contractor agrees to pay all state sales and use taxes. The Contractor for this project shall be licensed in the State of Idaho as a general contractor. A Public Works Contractors License for the State of Idaho is required to work on this work. All bids shall include a Bid Bond in the amount of 5% of the bid made out to the City of Post Falls. The Contract requires a performance and payment bond in the amount of 100% of the contract value. The Bidder shall assume responsibility for all costs, loss, damage and liabilities incurred as a result of, or arising out of, responding to this Request for Proposal. The Bidder shall submit all Requests for Information (RFI) in writing to the Architect. The Architect's response(s) to any questions will be issued to all Bidders unless the Bidder submitting the RFI provides a satisfactory justification as to why the Architect should limit its response to that Bidder. RFI's must be submitted no later than Friday, January 12, 2018 by the close of business. The Architect will issue responses no later than the close of business on Tuesday, January 16, 2018. Some questions may not be answered due to the time limitations. Any addenda issued by the Architect during the proposal development time shall be acknowledged in the space provided on the bottom of the proposal by listing the addenda date. The addenda content will be incorporated into the Agreement between the PFPD and the successful bidder. Contractor shall notify the Owner seven (7) days prior to the start of construction. Construction work shall not begin before the PFPD provides a Notice to Proceed and shall be completed no later than July 31, 2018. The City of Post Falls is an Equal Opportunity Employer. The City of Post Falls City Council hereby notifies all firms that no person or organization shall be discriminated against on the basis of race, religion, color, age, sex or national origin in consideration for an award issued pursuant to this advertisement. To the extent, Respondent intends to subcontract any of the work subject to this notice, the Respondent must include this notice in any agreements with subcontractors. The PFPD reserves the right to reject any and all bids. Dated this 18th day of January, 2018. CDA LEGAL 8942 JANUARY 20, 22, 2018

NOTICE OF TRUSTEE'S SALE TS No: ID-17-797200-SH NOTICE IS HEREBY GIVEN that on 5/30/2018, at the hour of 9:00 AM of said day, At the La Quinta Inn & Suites Coeur d'Alene, located at 333 W. Ironwood Drive, Coeur d'Alene, ID 83814. In the Auction.com Room, said Trustee will sell at public auction to the highest bidder, for cash in lawful money of the United States of America, all payable at the time of sale, the following described real property situated in the County of KOOTENAI, State of Idaho, and described as follows, to-wit: LOT 7, BLOCK 2, ATLAS ACRES, ACCORDING TO THE PLAT RECORDED IN BOOK "F" OF PLATS AT PAGE 71, RECORDS OF KOOTENAI COUNTY, IDAHO. 1998, GOLDENWEST, MODEL OK48001F, SERIAL NO. GWOR23N21149, HUD TAG NOS. ORE 366947 AND ORE 366946. The Trustee has no knowledge of a more particular description of the above-described real property, but for purposes of compliance with Idaho Code Section 60-113, the Trustee has been informed that the street address of 16682 NORTH RADIAN ROAD, RATHDRUM, ID 83858 may sometimes be associated with said real property. Said sale will be made, without covenant or warranty regarding title, possession or encumbrances, to satisfy the obligation secured by and pursuant to the power of sale conferred in the Deed of Trust made and entered into on 3/25/2004, by and among KENNETH W. AKINS AND SHARON L. AKINS, HUSBAND AND WIFE, as Grantor, and PIONEER TITLE COMPANY OF ADA COUNTY, as Trustee, and WELLS FARGO HOME MORTGAGE, INC., as Beneficiary; said Deed of Trust having been filed of record on 3/31/2004, as Instrument No. 1867209 Official Records of KOOTENAI County, Idaho. The naming of the above Grantor(s) is done to comply with Idaho Code Sections 45-1506(4)(a); no representation is made as to the responsibility of Grantor(s) for this obligation. The default for which this sale is to be made is: The monthly installment of $621.45, which may include principal, interest and escrow, due on 2/1/2017, and all subsequent installments of principal and interest through the date of this Notice, plus amounts that are due for late charges, delinquent property taxes, insurance premiums, advances made on senior liens, taxes and/or insurance, trustee's fees, and any attorney fees and court costs arising from or associated with the beneficiaries efforts to protect and preserve its security, all of which must be paid as a condition of reinstatement, including all sums that shall accrue through reinstatement or pay-off. Nothing in this notice shall be construed as a waiver of any fees owing to the Beneficiary under the Deed of Trust pursuant to the terms of the loan documents. The balance due and owing as of the date hereof on the obligation secured by said Deed of Trust is the amount of $71,276.21 in principal; plus accrued interest at the rate of 5.1250 percent per annum from 2/1/2017 adjusting, if at all, pursuant to the terms of the note; plus service charges, late charges, and any other costs or expenses associated with this foreclosure as provided by the Deed of Trust or Deed of Trust Note, or by Idaho law. TS No: ID-17-797200-SH Dated this 12th day of January, 2018. Robert W. McDonald, Esq, Trustee By: IDSPub #0136191 CDA LEGAL 8927 JANUARY 22, 29, FEBRUARY 5, 12, 2018

NOTICE OF TRUSTEE'S SALE TS No: ID-17-797179-SH NOTICE IS HEREBY GIVEN that on 5/29/2018, at the hour of 10:00 AM of said day, Veterans Memorial Plaza North Entrance Admin Building 451 N Government Way Coeur d'Alene ID 83815 , said Trustee will sell at public auction to the highest bidder, for cash in lawful money of the United States of America, all payable at the time of sale, the following described real property situated in the County of KOOTENAI, State of Idaho, and described as follows, to-wit: LOT 9, BLOCK 3, SIMM'S ADDITION TO THE TOWN OF COEUR D'ALENE, ACCORDING TO THE AMENDED PLAT RECORDED IN BOOK "B" OF PLATS AT PAGE 57, RECORDS OF KOOTENAI COUNTY, IDAHO. The Trustee has no knowledge of a more particular description of the above-described real property, but for purposes of compliance with Idaho Code Section 60-113, the Trustee has been informed that the street address of 1510 NORTH 3RD STREET, COEUR D ALENE, ID 83814-3309 may sometimes be associated with said real property. Said sale will be made, without covenant or warranty regarding title, possession or encumbrances, to satisfy the obligation secured by and pursuant to the power of sale conferred in the Deed of Trust made and entered into on 11/22/2005, by and among DEBORAH, GILMORE, AN UNMARRIED PERSON, as Grantor, and LANDAMERICA LAWYERS TITLE OF KOOTENAI COUNTY, as Trustee, and WELLS FARGO BANK. N.A. , as Beneficiary; said Deed of Trust having been filed of record on 11/28/2005, as Instrument No. 1997665 Official Records of KOOTENAI County, Idaho. The naming of the above Grantor(s) is done to comply with Idaho Code Sections 45-1506(4)(a); no representation is made as to the responsibility of Grantor(s) for this obligation. The default for which this sale is to be made is: The monthly installment of $971.02, which may include principal, interest and escrow, due on 4/1/2017, and all subsequent installments of principal and interest through the date of this Notice, plus amounts that are due for late charges, delinquent property taxes, insurance premiums, advances made on senior liens, taxes and/or insurance, trustee's fees, and any attorney fees and court costs arising from or associated with the beneficiaries efforts to protect and preserve its security, all of which must be paid as a condition of reinstatement, including all sums that shall accrue through reinstatement or pay-off. Nothing in this notice shall be construed as a waiver of any fees owing to the Beneficiary under the Deed of Trust pursuant to the terms of the loan documents. The balance due and owing as of the date hereof on the obligation secured by said Deed of Trust is the amount of $123,204.90 in principal; plus accrued interest at the rate of 4.7500 percent per annum from 4/1/2017 adjusting, if at all, pursuant to the terms of the note; plus service charges, late charges, and any other costs or expenses associated with this foreclosure as provided by the Deed of Trust or Deed of Trust Note, or by Idaho law. TS No: ID-17-797179-SH Dated this 12th day of January, 2018. Robert W. McDonald, Esq, Trustee By: IDSPub #0136192 CDA LEGAL 8928 JANUARY 22, 29, FEBRUARY 5, 12, 2018

SELF STORAGE LIEN SALE River Rock Self Storage - 650 N. Idahline Rd, Post Falls, ID 83854 intends to hold an auction of the goods stored in the following unit, which is in default for non-payment of rent. The sale will occur as an online auction via www.storagetreasures.com on 2/05/2018 at 11:45 pm. Unit 8, rented by Audrey Goodson of PO Box 432, Kellogg, ID 83837. The contents are described as "3 beds, assorted boxes, desk, dresser, Huffy bicycle, microwave, lawn chairs, blankets, television, etc." CDA LEGAL 8943 JANUARY 22, 29, 2018

NOTICE TO CREDITORS (I.C. 15-3-801) Case No. CV18-481 IN THE DISTRICT COURT OF THE FIRST JUDICIAL DISTRICT STATE OF IDAHO, IN AND FOR THE COUNTY OF KOOTENAI In the Matter of the Estate of CALVIN FENTER, Deceased. NOTICE IS HEREBY GIVEN that the undersigned has been appointed Personal Representative of the above-named decedent. All persons having claims against the decedent or the estate are required to present their claims within four months after the date of the first publication of this Notice or said claims will be forever barred. Claims must be presented to the undersigned at the address indicated, and filed with the Clerk of the Court. DATED this 10 day of January, 2018. /S/: THERESA A. KIMBALL c/o Steven O. Anderson Stamper Rubens, PS 720 W. Boone, Suite 200 Spokane, WA 99201 CDA LEGAL 8938 JANUARY 22, 29, FEBRUARY 5, 2018

Print Article

Read More Legals

Legals February 20, 2018

February 20, 2018 at 5:00 am | NOTICE TO CREDITORS (I.C. 15-3-801) Case No. CV-18-1130 IN THE DISTRICT COURT OF THE FIRST JUDICIAL DISTRICT OF THE STATE OF IDAHO, IN AND FOR THE COUNTY OF KOOTENAI IN THE MATTER OF THE ESTATE OF Mi...

Read More

Legals February 19, 2018

February 19, 2018 at 5:00 am | N O T I C E O F L E T T I N G Sealed proposals will be received by the IDAHO TRANSPORTATION BOARD only at the office of the IDAHO TRANSPORTATION DEPARTMENT, 3311 WEST STATE STREET, BOISE, IDAHO 83703...

Read More

Legals February 17, 2018

February 17, 2018 at 5:00 am | NOTICE TO CREDITORS CASE NO. CV-17-9369 IN THE DISTRICT COURT OF THE FIRST JUDICIAL DISTRICT OF THE STATE OF IDAHO, IN AND FOR THE COUNTY OF KOOTENAI IN THE MATTER OF THE ESTATE OF: GLENN R. LUCAS, D...

Read More

Legals February 16, 2018

February 16, 2018 at 5:00 am | NOTICE OF TRUSTEE'S SALE On June 11, 2018 at the hour of 10:30AM, of said day, in the office of Alliance Title & Escrow Corp. located at 2157 N. Main St., Coeur d'Alene, ID 83814. Alliance Title & Es...

Read More

Contact Us

(208) 664-8176
215 N. Second St
Coeur d'Alene, Idaho 83814

©2018 The Coeur d'Alene Press Terms of Use Privacy Policy
X
X